Loading...
Serving Visalia, CA and surrounding areas. (559) 409-1729
Effective Date: January 1, 2026
These Terms and Conditions ("Terms") govern your use of the website located at visaliasunroomcontractor.com and your engagement with Precision Visalia Sunrooms ("we", "us", or "our") for sunroom contracting and related services. By accessing our website or requesting our services, you agree to be bound by these Terms. Please read them carefully.
If you have questions about these Terms, please contact us before proceeding.
By using this website or engaging our services, you confirm that you are at least 18 years of age, that you have the legal authority to enter into a binding agreement, and that you agree to comply with these Terms. If you do not agree to these Terms, you should not use this website or engage our services.
Precision Visalia Sunrooms provides residential sunroom contracting services in the Visalia, CA area, including but not limited to: sunroom additions, four-season rooms, three-season rooms, patio enclosures, screen room installation, patio-to-sunroom conversions, deck-to-sunroom conversions, solarium installation, patio cover installation, and related design and construction services.
All services are subject to a signed project contract, permit approvals, and site conditions. We reserve the right to decline any project that we determine is outside the scope of our capabilities or that presents conditions we cannot safely or properly address.
Free on-site estimates are provided at our discretion and do not constitute a binding contract. An estimate is a good-faith projection of costs based on the information available at the time of the site visit. Final pricing is confirmed only in a written, signed project contract.
Estimates may change if site conditions differ materially from what was visible during the initial visit, if the scope of work is modified at the customer's request, if permit requirements impose additional work, or if material costs change significantly between the estimate and the project start date.
Any change to the project scope or price must be documented in a written change order signed by both parties before additional work proceeds.
Project scheduling is confirmed in writing after a signed contract and any required deposit are received. Start dates are subject to permit approval timelines, weather conditions, and the availability of materials and labor. We will communicate schedule updates promptly and work to minimize delays.
If you need to cancel or postpone a project after signing a contract, please notify us in writing as soon as possible. Deposits may be non-refundable depending on the stage of the project and any costs already incurred for materials, permit fees, or labor scheduling. Specific cancellation terms will be stated in your project contract.
We reserve the right to postpone or reschedule work due to weather events, unsafe site conditions, permit delays outside our control, or other circumstances beyond our reasonable control.
Payment terms are outlined in your project contract. Typically, a deposit is required at the time of contract signing, with additional payments due at defined project milestones, and a final payment due upon substantial completion and your acceptance of the finished work.
All invoices are due upon receipt unless otherwise stated in your contract. Late payments may be subject to a service charge. We accept payment by check, bank transfer, and other methods listed in your contract.
Failure to make timely payments may result in a suspension of work until the account is brought current. Outstanding balances owed to us may be subject to a mechanics lien on your property as permitted by California law.
We obtain all required building permits on your behalf as part of our contracted services. You agree to cooperate with the permit process, including providing access to your property for required inspections and signing any documents required by the local building authority.
If your property is subject to HOA rules, it is your responsibility to obtain any required HOA approvals before work begins. We can assist you in preparing documentation for your HOA, but we cannot be responsible for delays caused by HOA review processes.
We stand behind our workmanship. Specific warranty terms, including duration and coverage, are stated in your project contract. Workmanship warranties are limited to defects in installation or construction caused by our work and do not cover damage caused by misuse, neglect, acts of nature, or modifications made by parties other than us after project completion.
Manufacturer warranties on materials, windows, doors, and components are separate from our workmanship warranty and are subject to the terms issued by each manufacturer. We will assist you in filing a manufacturer warranty claim where applicable.
To the fullest extent permitted by applicable law, our total liability to you for any claims arising from or related to our services shall not exceed the total amount you paid us for the specific project giving rise to the claim.
We are not liable for indirect, incidental, consequential, special, or punitive damages, including lost profits, loss of use, or damage to property not directly caused by our work, even if we have been advised of the possibility of such damages.
Except for the express workmanship warranty stated in your project contract, all services and materials are provided on an "as is" basis. We disclaim all implied warranties, including implied warranties of merchantability and fitness for a particular purpose, to the fullest extent permitted by law. No oral statement by any employee or representative creates any warranty not stated in the written project contract.
We value our customers and prefer to resolve any disagreement directly and informally. If you have a concern, please contact us first and give us a reasonable opportunity to address it before pursuing formal remedies.
If informal resolution is not possible, any dispute arising from these Terms or from our services shall be resolved through binding arbitration in Visalia, California, under the rules of a mutually agreed-upon arbitration service, unless both parties agree in writing to resolve the dispute another way.
Nothing in this section prevents either party from seeking emergency injunctive or other equitable relief in a court of competent jurisdiction where necessary to prevent irreparable harm.
These Terms and any disputes arising from them are governed by the laws of the State of California, without regard to its conflict of law provisions. Any legal action not subject to arbitration shall be brought in a court of competent jurisdiction located in California.
You may use our website for lawful purposes only. You agree not to use this website in any way that could damage, disable, overburden, or impair it, or interfere with any other party's use of it. You may not attempt to gain unauthorized access to any part of the website or its related systems.
The content on this website - including text, images, and layout - is owned by Precision Visalia Sunrooms and may not be reproduced, distributed, or used for commercial purposes without our written permission.
We may update these Terms from time to time. When we do, we will post the revised Terms on this page with a new effective date. Your continued use of our website or services after a change constitutes your acceptance of the updated Terms. We encourage you to review this page periodically.
If you have questions about these Terms, please contact us.
Precision Visalia Sunrooms
511 W Race Ave
Visalia, CA 93291